Prime’s Failure to Secure Subcontractor, Not Protest Delay, Caused Increased Costs; ASBCA No. 61074, Appeal of CDM Constructors Inc.
The government’s motion for summary judgment in an appeal of an agency’s denial of a claim for increased costs is granted, where a 60-day suspension of work after a bid protest was not the reason the contractor lost the services of a lower-cost subcontractor.
🔒 Members Only · Protests & Claims BriefYou’ve reached the member portion of this brief.Members read the full analysis and the source documents in every Brief, six days a week.